Terms and Conditions for Cafone Contractors, LLC
Introduction

Welcome to Cafone Contractors, LLC ("Cafone," "we," "us," or "our"). By using our services, you agree to be bound by these terms and conditions, as well as any amendments or modifications thereto (collectively, the "Terms"). These Terms apply to all services provided by Cafone Contractors, which specializes in home additions and renovations. Please read these Terms carefully before using our services. If you do not agree with any part of these Terms, you should not engage our services.

1. Services Provided

Cafone Contractors is a company based in New Jersey dedicated to delivering high-quality home additions, renovations, and remodeling services. Our offerings include but are not limited to:

Home additions, Kitchen and bathroom renovations, Basement finishing, Custom home remodeling, Interior and exterior home improvements, Residential and commercial renovations.

Our team of experts will work closely with you to ensure that your vision is brought to life with professional craftsmanship and attention to detail.

2. Contact Information

For inquiries, scheduling consultations, or any customer service needs, please contact us at:

Phone: (973) 641-1034

Email:

[email protected]

Office Address: 11 Spielman Road, NJ, 07004

We are available during regular business hours to assist with any questions or concerns. If you need urgent support, please reach out via phone.

3. Project Agreement

Before any work begins, a project agreement will be drafted between you (the "Client") and Cafone Contractors. This agreement will outline the scope of work, estimated timeline, payment terms, and other specific conditions that pertain to your project. Both parties must sign the agreement before work commences.

4. Payment Terms

Payment for services will be determined and agreed upon in the project agreement. We accept various payment methods, including but not limited to check, credit card, or bank transfer.

A deposit may be required before work begins.Progress payments may be required as the project advances. Final payment will be due upon the satisfactory completion of the work.

Please refer to the specific payment schedule outlined in your project agreement.

5. Changes to the Scope of Work

In some cases, the scope of work may change during the course of a project due to unforeseen circumstances or changes requested by the Client. Any changes to the scope will require a written agreement, and additional costs may be incurred.

6. Project Timeline

Cafone Contractors will make every reasonable effort to complete the project within the specified timeline as outlined in the project agreement. However, we are not responsible for delays caused by factors beyond our control, including but not limited to:

Weather conditions, Supply chain issues, Client-requested changes. Permitting delays

In such cases, we will inform the Client of any delays and provide a revised timeline if necessary.

7. Permits and Approvals

The Client is responsible for obtaining any necessary permits and approvals required for the project. Cafone Contractors may assist in coordinating with local authorities, but the Client is ultimately responsible for ensuring compliance with all local building codes, zoning laws, and other regulatory requirements.

8. Warranties and Guarantees

Cafone Contractors provides a warranty on our work for a period of one (1) year from the date of project completion. This warranty covers defects in workmanship but does not cover damages resulting from misuse, accidents, or normal wear and tear. Manufacturer warranties for materials used in your project will be honored, and we will assist in the warranty claims process where applicable.

9. Client Responsibilities

As a Client, you agree to provide access to your property during regular working hours, provide necessary information, and make timely payments in accordance with the payment terms in the project agreement. You also agree to notify Cafone Contractors of any issues or concerns during the project in a timely manner.

10. Liability and Insurance

Cafone Contractors maintains appropriate insurance coverage to protect both the company and the Client during the course of the project. Our insurance includes:

General liability insurance, Workers' compensation insurance, Property damage insurance

While we take all necessary precautions to minimize risk, Cafone Contractors will not be held liable for any damages caused by factors beyond our control, including accidents, natural disasters, or acts of third parties.

11. Termination of Agreement

Either party may terminate the project agreement with written notice. In the event of termination, the Client will be responsible for payment for all work completed up to the point of termination, as well as any materials ordered in advance. Cafone Contractors will provide the Client with a final invoice reflecting these charges.

12. Dispute Resolution

In the event of a dispute between Cafone Contractors and the Client, we encourage open communication to resolve any issues. If a resolution cannot be reached, the parties agree to mediate the dispute before pursuing legal action.

13. Privacy and Confidentiality

Cafone Contractors respects your privacy. We will not share your personal information with third parties without your consent, except as required by law. Any confidential information shared during the course of the project will be protected to the best of our ability.

14. Indemnification

The Client agrees to indemnify and hold Cafone Contractors harmless from any claims, damages, liabilities, and expenses arising from the Client’s misuse of services, failure to comply with terms, or violation of applicable laws.

15. Governing Law

These Terms shall be governed by and construed in accordance with the laws of the State of New Jersey. Any disputes arising out of or related to these Terms will be subject to the exclusive jurisdiction of the courts in New Jersey.

16. Modifications to Terms

Cafone Contractors reserves the right to modify these Terms at any time. Any changes will be communicated to the Client in writing. By continuing to use our services after such modifications, you agree to be bound by the updated Terms.

Conclusion

By engaging Cafone Contractors for your home addition and renovation needs, you agree to the above Terms and Conditions. We are committed to providing excellent service and high-quality craftsmanship throughout your project.

If you have any questions regarding these Terms or our services, please contact us at the details provided.

Cafone Contractors, LLC